Welcome to CleanBuildPoint. These Terms and Conditions govern your use of our automatic gate system installation services and website. By engaging our services or accessing our website, you agree to be bound by these terms.
In these Terms and Conditions, unless the context otherwise requires:
CleanBuildPoint specializes in the professional installation of automatic gate systems for residential, commercial, and industrial properties. Our services include but are not limited to:
Important: All installations are performed in accordance with Italian safety regulations and European CE standards. The specific scope of work will be detailed in individual quotations and service agreements.
All quotations provided by CleanBuildPoint are valid for a period of 30 days from the date of issue unless otherwise specified. Quotations are based on the information provided by the Client and site conditions at the time of assessment.
We reserve the right to adjust pricing if:
Any price adjustments will be communicated to the Client in writing and require approval before proceeding with the affected work.
Payment for our services shall be made according to the following schedule unless otherwise agreed in writing:
Late Payment: Invoices are due within 15 days of issue. Late payments may incur interest charges at a rate of 8% per annum above the European Central Bank base rate. We reserve the right to suspend services for accounts with overdue payments.
To ensure successful completion of the installation, the Client agrees to:
CleanBuildPoint will make reasonable efforts to complete installations within the estimated timeframe provided. However, completion dates are estimates and not guaranteed delivery dates unless explicitly stated as such in writing.
We shall not be liable for delays or failure to perform our obligations due to circumstances beyond our reasonable control, including but not limited to: severe weather conditions, natural disasters, strikes, material shortages, supplier delays, pandemics, government restrictions, or other force majeure events.
CleanBuildPoint guarantees all installation workmanship for a period of 24 months from the date of completion. This warranty covers defects in installation but does not cover damage caused by misuse, neglect, unauthorized modifications, or normal wear and tear.
Automatic gate systems and components are covered by the manufacturer's warranty, typically ranging from 12 to 36 months depending on the brand and product. Full warranty details will be provided with the installation documentation.
Warranties do not cover:
CleanBuildPoint maintains comprehensive professional liability insurance and public liability insurance as required by Italian law. Our liability is limited as follows:
Our total liability for any claim arising from our services shall not exceed the total amount paid by the Client for the specific project giving rise to the claim. We shall not be liable for any indirect, consequential, or incidental damages including but not limited to loss of profits, business interruption, or loss of data.
The Client agrees to indemnify and hold harmless CleanBuildPoint against any claims, damages, or expenses arising from the Client's failure to obtain necessary permits, permissions, or comply with applicable regulations.
Clients may cancel projects with the following penalties:
We reserve the right to terminate the Agreement if the Client breaches these Terms and Conditions, fails to make payments as agreed, or if site conditions make safe completion of the work impossible.
We strongly recommend regular maintenance of automatic gate systems to ensure optimal performance and safety. CleanBuildPoint offers maintenance contracts that include:
All automatic gate systems installed by CleanBuildPoint comply with European safety standards including EN 12453, EN 12445, and EN 13241-1. Safety features include obstacle detection, emergency stop functions, and appropriate warning signage.
Clients are responsible for ensuring that all users of the automatic gate system are properly trained in its safe operation and that regular safety checks are performed as outlined in the user manual.
All designs, drawings, specifications, and technical documentation created by CleanBuildPoint remain our intellectual property. Clients receive a non-exclusive license to use such materials solely for the operation and maintenance of their installed system.
We collect and process personal data in accordance with the General Data Protection Regulation (GDPR) and Italian data protection laws. Client information is used solely for the purpose of providing our services and will not be shared with third parties except as necessary for service delivery or as required by law.
In the event of any dispute arising from these Terms and Conditions or the provision of our services, the parties agree to first attempt resolution through good faith negotiation. If negotiation fails, disputes shall be resolved through mediation before resorting to litigation.
These Terms and Conditions shall be governed by and construed in accordance with the laws of Italy. Any legal proceedings shall be subject to the exclusive jurisdiction of the courts of Milano, Italy.
CleanBuildPoint reserves the right to modify these Terms and Conditions at any time. Changes will be effective immediately upon posting to our website. Clients will be notified of material changes via email. Continued use of our services after modifications constitutes acceptance of the updated terms.
If any provision of these Terms and Conditions is found to be invalid or unenforceable by a court of competent jurisdiction, such provision shall be severed, and the remaining provisions shall continue in full force and effect.
These Terms and Conditions, together with any written quotations, service agreements, and invoices, constitute the entire agreement between CleanBuildPoint and the Client, superseding all prior discussions, negotiations, and agreements.
For questions regarding these Terms and Conditions or our services, please contact us:
CleanBuildPoint
Via della Moscova, 20
Milano, 20121
Italy
Phone: